Delay analysis, EOT and adjudication work, anonymised. Each case study sets out the problem, the analysis and the outcome.

Delay analysis upheld: circa £0.7m adjudication decision for the contractor on a £5m NEC3 highway scheme

Adjudication · NEC3 ECC · Highways. The Employer levied delay damages and claimed the contractor had been overpaid. The contractor’s contemporaneous programme record, and a point-by-point rebuttal of the Employer’s time assessments, carried the decision. Read the case study →

Extension of time recovered in full: nil assessment on 4 of 5 delay events overturned on a local authority highway scheme

Extension of time · Civil engineering conditions · Highways. The employer’s consultant assessed nil time and nil cost for 4 of 5 delay events. The delay analysis showed the contractor’s mitigation work had been misread as proof the delay wasn’t critical, and the extension was granted in full. Read the case study →